ML20098C976: Difference between revisions
StriderTol (talk | contribs) (StriderTol Bot insert) |
StriderTol (talk | contribs) (StriderTol Bot change) |
||
Line 76: | Line 76: | ||
Moreover, Permittee has committed to the NRC Staff that: | Moreover, Permittee has committed to the NRC Staff that: | ||
the final design of WNP-1 will satisfy the requirements of any future regulations promulgated between the date I | the final design of WNP-1 will satisfy the requirements of any future regulations promulgated between the date I | ||
. of docketing and the resumption of construction of WNP-I from which WNP-1 wot.la otherwise be grandf athered by virtue of its date of docketing. A Supply System letter dated June 11, 1982 makes that comittment... | . of docketing and the resumption of construction of WNP-I from which WNP-1 wot.la otherwise be grandf athered by virtue of its date of docketing. A Supply System {{letter dated|date=June 11, 1982|text=letter dated June 11, 1982}} makes that comittment... | ||
1 Letter to R. Ferguson, WPPSS from D.G. Eisenhut -NRR, NRC, July 16, 1982. Clearly with the committment refered to above, four years (over , | 1 Letter to R. Ferguson, WPPSS from D.G. Eisenhut -NRR, NRC, July 16, 1982. Clearly with the committment refered to above, four years (over , | ||
and above the time for construction halt) is not sufficient time in which to build the plant. The time requested for the extention is not reasonable, nor is it adequate, and further requests for extensions would be even more reasonable. - | and above the time for construction halt) is not sufficient time in which to build the plant. The time requested for the extention is not reasonable, nor is it adequate, and further requests for extensions would be even more reasonable. - |
Latest revision as of 10:24, 24 September 2022
Text
g wum UNITED STATES OF AMERICA NUCLEAR REGULATORY COMMISSION hou BEFORE THE ATOMIC SAFETY AND LICENSING BOARD k In the Matter of kf[f n WASHINGTON PUBLIC POWER SUPPLY SYSTEM, ) Docket No. 50-460 CPA
. )
43
_e t . _a_l_.
)
(WPPSS Nuclear Project No. 'l) )
COALITION FOR SAFE POWER AMENDED CONT _ENTION NO. 2 - FEB 11, 1983 Pursuant to the Atomic Safety and Licensing Board Order of January 26, 1983 Petitioner Coalition for Safe Power hereby submits its amended contention No. 2. TR at 69.
CFSP 2 Petitioner contends that the Permitee's decision in April 1982 to
" defer" co nstruction for two to five years, and the subsequent cessation of construction at WNP-1, was dilatory. Such action was without " good cause" as required by 10 CFR 50.55(b). Moreover, the modified request for extension of completion date to 1991 does not constitute a " reasonable period of time" provided for in 10 CFR 50.55(b).
On April 29, 1982, the Board of Directors of the Washington Public .
Power Supply System voted to suspend construction of WNP-1,for a two
\ .
to five year period. This decision was made upon reviewing the recommen-dations of the Bonneville Power Adminstration (BPA), rev'iewing alternative proposals and taking public coment. Letter to H. Denton., Director-of NRR, NRC from G.D. Bouchey, WPPSS, April 30, 1982. Eight and one half months later, following receipt of Petitioner's contention 2 in this case, Permittee notified the NRC that it was modifying its ,
jh request from a completion date of 1986 to 1991. Letter to H. Denton, fn Director NRR, NRC from G.D. Bouchey, WPPSS, January 11, 1983. This ncy S action (along with its requisite paperwork) was taken with the full D intention of delaying completion of the plant and thus was " dilatory" W within the definition provided by Black's Law Dictionary, o2E Such actions also were without " good cause" as required by Section 50.55(b). Permittee has not specified exactly what it believes constitutes
2- -
its basis for " good cause". In its Letter, supra of April 1983. WPPS$
states:
. Because BPA support is essential to the financing of cil three Surnly System projects, the Board (of Directors) voted to acc'ept the BPA reconnendations [to halt construction).
The January,1983 Letter, supra merely states that BPA had recommended suspension of construction of WNP-1 from two to five years and it was in view of that recommendation that the WPPSS Board voted to suspend construction. At the Prehearing Conference on January 26, 1983, Permittee's Counsel stated that the reason was lack of need for power from WNP-
) 1. TR at 60. Counsel also stated that BPA has the authority to disapprove i
any further financing of WNP-1 construction. TR at 70 BPA is not a part of WPPSS management, as was pointed out by Permit-
, tee's Counsel.' TR at 77. ll wither does BPA have the authority to control WPPSS finances. The Intial Decision of the licensing board for WNP-1 (Construction Permit), LBP-75-72, 2 NRC 922 at 926 states:
Permanent financing is effected by the issuance of tax
- exempt long term debt securities. WPPSS debt securities i
are of the revenue note (short term) and revenue bond (long
! term) variety. State of Washington law provides that WPPSS may issue revenue bonds or warrants payable from the revenues of the Utility properties operated by it. ,
The Initial Decision does not include a finding that 8PA need approve or can disapprove any financing for WNP-1. Furthermore, Permittee has never stated in its submittals to the ERC that BPA could or might disapprove financing for the plant. The vague, conclusionary and unsubstan-4 tlated statement that BPA support is essential to the financing of the WPPSS projects, as quoted above, is all Permittee offers. While this may be Permittee's suggestion of what constitutes " good cause" for its actions, it is neither clear that it is nor is it supported by fact. -
Need for power was offered as a reason for " good cause" by Permittee's I a
e- .,
e Counsel at the Prehearing conference. TR at 60. Nowhere else, including the SPA's Report " Analysis of Resource Alternatives" dated April 19,
'1982, has this arguement been advanced. IN fact WPP55 asserts the s
need for power from the plant does exist. See Letter, supra of April, "1982 . The Pacific Northwest Utiliti.es Conference (PNUCC), in its " Northwest Regional Forecast of Power Loads and Resources. July 1982-June 1983" issued in May, 1982 and relied upon by Permittee and other Northwest ,
utilities (See n Skagit/Hanford Environmental Report) shows that WNP-1 will be needed prior to the dates of completion. Forecast, Table 1.1 and Figure 1-2. Furthmore, the SPA Report, supra at 3 states:
A number of utility executives and experts believe it is prudent utility practice to plan resources to meet loads in the high portion of the forecasting range. Under these circumstances, and using the high range recomended, all three not billed projects could prove to be needed on schedule.
Section 50.55(b) of Title Ten, Code of Federal Regulations states explicitly that a completion date can be extended by the Comission "for a reasonable period of time." Construction of the plant is little over half completed. By 1981. Permittee had already projected the -
need for another 65 months over an original expected construction schedule of 60 months. WPP55 Inquiry at 20. Now Permittee wishes to add another _
two to five years resulting in a delay (over the expected completion data) of seven to ten years, and a delay (past the Construction Permit expiration date) of six to nine years. This latter calculation is
. in the range of double the outside anticipated construction period. ,
Six to nine years cannot have been contemplated as a " reasonable period of time" by the writers of 10 CFR 50.55(b). ,
Furthermore, there is ample reason to believe that the dates for
/ constructi A
completion as they stand presently will not be adequate,
- retttioner does not subscribe to either the BPA or PNUCC forecasts and does not believe the power from WNP-1 will ever be needed.
4 necessitating further unreasonable extentions. At the time of con
? struction halt at WNP-1, work had progresscJ at approximately 9)% per year. If, construction is halted for the full five years contemplated, four years will remain to complete the remaining 40% of the plant. ,
This will not be sufficient taking into consideration Permittee's history.
Moreover, the WPPSS Inquiry (at 19-23) addressed the ability of WPPSS to meet schedule deadlines:
4 The rate of delay in plant completion is accel'eratir.g...
AstudypreparedbyWPP$5'indicatesthereislittlemore than remote likelihood that the officially adopted schedulei can, in fact, be met.
Schedule delays have a direct impact on the overall cost of the projects....These extentions expose construction costs to the impact of increasing inflation.
The low probabilities of achieving the schedules, as established by the risk analysis, were not discussed by the Board (of
. Directors) when the schedules were adopted.
The Comittee was unable to find evidence that the officially adopted completion dates for the plants are used by WPSS management to monitor or control the progress of work at the plant sites. ,
Moreover, Permittee has committed to the NRC Staff that:
the final design of WNP-1 will satisfy the requirements of any future regulations promulgated between the date I
. of docketing and the resumption of construction of WNP-I from which WNP-1 wot.la otherwise be grandf athered by virtue of its date of docketing. A Supply System letter dated June 11, 1982 makes that comittment...
1 Letter to R. Ferguson, WPPSS from D.G. Eisenhut -NRR, NRC, July 16, 1982. Clearly with the committment refered to above, four years (over ,
and above the time for construction halt) is not sufficient time in which to build the plant. The time requested for the extention is not reasonable, nor is it adequate, and further requests for extensions would be even more reasonable. -
Thus, there exists no record to show that Permittee's actions to suspend the construction are "beyond the control of the permit holder"
1 i
as required for a finding of " good cause" under 50.55(b) or that the time requested is reasonable. Such actions as were taken by the Permittee were intentional and therefore " dilatory".
Respectfully submitteu, Dated this day the lith of February, 1983 C - 3,</ _
Mina Bell. CF5P 9 I e
e e
a q b e
1 x . _ - - _ _ _ _ - _ - - _ _ - - - _ _ - _ _ _ - _ _ - _ _ - __ .. _ .
l 'e a e c .
- UNITED STATES OF. AMERCIA NUCLEAR REGULAT01Y CO PISSION I
BEFORE THE ATOMIC SAFETY AND LICENSING BOARD In the Matter of )
) Docket No. 50-397CP WASHINGTON PUBLIC POWER SUPPLY SYSTEM ) 50-460CP (WNP-l&2) ) -
)
CERTIFICATE OF SERVIC E
.e.
I hereby certify that copies of " COALITION FOR SAFE POWER AMENDED CONTENTION NO. 2 - FEB. 11, 1983" in the above-captioned proceeding have been served on the following by deposit in the U.S. Mail, first class, postage prepaid, on this lith day of Februarf, 1983:
P Herbert GRossman, Chairman # Nicholas S. Reynolds ASLB Debevoise & Lieberman USNBC 1200 Seventeenth St, N.W.
Washin6 ton, D.C. 20555 ,
Suite 700 Washington, D.C. 20036 '
Glen 0, Bright Administrative Judge ASLAB Panel ASLB USNRC USNRC Washington, D.C. 20555 Washington, d,c. 20555 State of Washington Dr. Jerry Harbour Energy Facility Site $ valuation Administrative Judge Couno 11 ASLB Mail Stop PY-11 -
USNRC Olympis, Wa, 98504 Washington, D.C. 20555 Decketing and Service Section -
William D. Paton, Esq.
OS N'iC Washington, D.C. 20555 Offi
- f th* E** "ti"*
Legal Director .
U.S. Nuclear Regulatory Gerald C. Sorensen Commission
' Manager, Licens ing Frogram Washington, D.C. 20555 WPPSS 300 George Washington Way Richland, Wa, 99352
, p?
- M ina Bell -
Intervenor for CFSP l
.____._.__.__..._...__.___._._.u
S .2./. - P 3
~
l w & P-1 JW 4 4 L 9yJ 43 Aa& /r- /
P M P I ar.ay n,e.
Wi~-ni,G A7/4 ,>>o fg X A'It*/
~ *%-
- f~ . 77' cw-~ u awsxeis acf.'ta c ep}sf y& .2&Xf+ < A. J>L F A (
l c-l UNITED STATES
/* *g' S ,
[ <.
f NUCLEAR REGULATORY COMMISSION W ASHINGTON, D. C. 20665 i , ,, j OFFECE OF STATE PROGRAMS R3
\ &f D<atc2LJ - m J1-
'2- All. LLnk w%'P-J.
Mi 7
, _ . . . _ . . _ . _ _ . , _ - . . .