ML20009G871

Fourth Set of Interrogatories Directed to Businessmen for Public Interest,Inc Re Basis for Allegations & Disagreements W/Nrc Evaluation of Request for CP Extension.Related Correspondence

ML20009G871
Person / Time
Site:	Bailly
Issue date:	07/30/1981
From:	Eichhorn W EICHHORN, EICHHORN & LINK, NORTHERN INDIANA PUBLIC SERVICE CO.
To:	BUSINESS & PROFESSIONAL PEOPLE FOR THE PUBLIC INTERES
References
NUDOCS 8108050165
Download: ML20009G871 (7)

Text

.. .

9- a g k RELATED CORRESPONDENCE '

. ,p S r

UNITED STATES OF AMERICA '9' $\

'i 2 ^UC NUCLEAR REGULATORY COMMISSION 31981 >

' '% h,m,, '2)

R G' ' ' -

< 2. ta /

BEFORE THE ATOMIC SAFETY AND LICENSING BOARD g 'd

/f

~ n In the Matter of ) Docket No. 50-367

)

NORTHERN INDIANA PUBLIC ) (Construction Permit SERVICE COMPANY ) Extension) -

) f (Bailly Generating Station, ) July 30, 1981 hs F 1/ V, Nuclear-1) ) i

'~

~ lu 0 11931 * .,=!

~*

u.s. >mun unMon NORTHERN INDIANA PUBLIC SERVICE COMPANY'S co " $sre FOURTH SET OF INTERROGATORILS TO . /' l BUSINESSMEN FOR THE PUBLIC INTEREST, INC. D .__

Northern Indiana Public Service Company (NIPSCO) hereby serves its Fourth Set of Interrogatories to Businessmen for the Public Interest, Inc. (hereinafter "BPI"), pursuant to 10 C.F.R. S 2.740b. Each interrogatory is to be answered fully in writing, under oath or affirmation, by an officer or agent of BPI and is to include all pertinent information known to BPI. Each answer should clearly indicate the interrogatory l

to which it is intended to be responsive.

Under NRC regulations (10 C.F.R. S 2.740 (e)) parties are required to supplement responses to interrogatories under certain

\

, circumstances when new and/or different information becomes avail-

'l able.

g s

/

8108050165 810730 PDR ADOCK 05000367 C PDR

In responding to these interrogatories, please include all information available to agents, employees, attorneys, investi-gators, and all other persons directly or indirectly subject in any way to the control of the person or organization to which these interrogatories are directed.

" Documents" means all written or recorded material of any kind or character known to BPI or in its possession, custody, or control, including, without limitation, letters,-correspond-ence, telegrams, memoranda, notes, records, minutes, contracte, agreements, records or notations of telephone or personal conver-sations or conferences, inter-office communications, microfilm, bulletins, circulars, pamphlets, studies, notices, summaries, reports, books, articles, treatises, teletype messages, invoices, tape recordings, and work-sheets.

When used with respect to a document, " identify" means, without limitation, to states its date, the type of document (egg., letter, memorandum, telegram, chart, photograph, sound reproduction, etc.), the author and addressees, the present location and the custodian, and a description of its contents.

When used with respect to a person, " identify" means, with-out limitation, to state his or her name, address, occupation, and professional qualifications.

4

If BPI cannot answer any portion of any of the Interroga-tories in full, after exercising due diligence to do so, so state, and answer to the extent possible, specifying the in-ability to answer the remainder and stating when BPI expects to be able to answer the unanswered portions.

NIPSCO'S INTEFROJATORIES A!

42. With respect to each item of conduct identified in your answer to Interrogatory 1(b) (1):

(a) Please specify the basis for your allegation that the conduct contributed to the failure to complete construction of Bailly by September 1, 1979; (b) Please explain how the conduct contributed to the failure to complete construction of Bailly by i

September 1, 1979; (c) Please specify the basis for your answer to Inter-rogatory 42(c).

43. (a) Please state whether each of the following supports your conclusion that " good cause" does not exist for the extension of the construction permit for Bailly:

/ Numbering of the following Interrogatories continues from Northern Indiana Public Service Company's Third Set of Interrogatories to Businessmen for the Public Interest, Inc. (June 22, 1981).

. , . _4_

4 (1) that the construction permit for Bailly was issued four months later than NIPSCO had predicted in 1973; (2) that NIPSCO did not commence remobilization of its contractors prior to completion of judicial review of the issuance of the con-struction permit for Bailly; (3) that a stay of construction of Bailly was issued by the U.S. Court of Appeals for Seventh Circuit; ,

(4) that a slurry wall was constructed for Bailly; (5) that the NRC Staff conducted a review of the pile foundation design for Bailly.

(b) Please provide a basis for your answers to Interroga-tory 43(a).

44. With respect to the "NRC Staff Evaluation of the Request for an Extension of Construction Permit CPPR-104 for the Bailly Generating Station, Nuclear 1" (July 17, 1981) , and the " Environmental Impact Appraisal Prepared by the Division of Licensing Regarding the Extension of Construction Permit CPPR-104 Bailly Generating Station, Nuclear-1" (July 17, 1981):

(a) Please specifically identify each statement or state-ments with which you disagree.

(b) In what respect do you disagree with each statement or statements identified in your answer to Interroga-tory 44 (a)?

(c) Please provide the basis for your answer to Inter-rogatory 44(b).

45. With respect to the " Assessment of the Influence of Dewater-ing at Bailly N-1" (Nov. 1980), prepared by D'Appolonia (Project No. MW 79-720):

(a) Please specifically ide-tify each statement or state-ments with which you disagree.

(b) In what respect do you disagree with each statement or statements identified in your answer to Interroga-tory 45(a)?

(c) Please provide the basis for your answer to Interroga-tory 44 (b) .

46. You have contended that the reason why Bailly was not completed by the latest completion date grows out of the lack of thorough and ade-quate planning and design by NIPSCO, its contractors and subcontractors. All of the delay growing out of the Staff's direction to NIPSCO to halt pile driving could have been avoided had NIPSCO and its contractors and subcontractors done a more thorough and careful job of planning for and designing the Bailly plant. More information about the geology of the site and the design of the foundation for a nuclear plant to be built on that site, and the method of constructing a foundation of that design could have avoided much of the delay in construction period since the construction permit was issued.*/

$! " Joint Intervenor's First Supplement to Petitiod For Leave to Intervene" (Feb. 26, 1980), p. 14.

(a) (1) Please specify the respects in which NIPSCO's

" planning and design" was not " thorough and adequate."

(2) Please provide a basis for your answer to Interrogatory 46(a) (1) .

(3) Please specify those actions which NIPSCO could have taken, but did not take, which would have rendered its " planning and design"

" thorough and adequate."

(b) Please specify the basis for your contention that the delay in constructicn of Bailly attributable to the halt in pile driving "could have been avoided had NIPSCO and its contractors and subcontractors done a more thorough and careful job of planning for and designing the Bailly plant."

(c) Please specifically identify the "information about the geology of the site and the design of the founda-tion for a nuclear plant to be built on that site, and the method of constructing a foundation of that design" to which you are referring.

(d) Are you contending that it was possible for LIP".O to have obtained the information identities 'n your answer to Interrogatory 46 (c) between the datt NIPSCO submitted its application for a construction permit for Bailly and the dakt of issuance of the construc-tion permit for Bailly? If yes, please provide a basis for your contention.

J (e) Are you contending that, if NIPSCO had obtained the information identified in your answer to Interroga-tory 46(c) prior to issuance of the construction permit for Bailly, the delay in construction of Bailly attributable to the halt in driving piles would not have occurred? If yes, please provide a basis for your answer.

47. Please identify each document to which you referred or upon which you relied in answering Interrogatories 42-46.

48. Please identify each person whom you consulted in answer-i ing Interrogatories 42-46 giving the following information for each such person:

(a) Name; (b) Address; (c) Place of employment and job title; (d) Number (including subpart) of each Interrogatory with respect to which that person consulted, aided or pro-vided or furnished information; and l (e) The nature of the information or aid furnished.

Respectfully submitted, i

EICHHORN, EICHHORN &. LINK 5243 Hohman Avenue Hammond, Indiana 46320

\

• pr By /j u.<_,,

l William H. Eichhorn j Attorneys for Northern Indiana j Public Service Company 1

LOWENSTEIN, NEWMAN, REIS

& AXELRAD 1025 Connecticut Avenue, N.W.

_... Washington, D.C~.20036-_. - .. . ... - . ... .- -~ . .

, _ . _ -. _._. -- . _ , - - - . _ -