|
---|
Category:LEGAL TRANSCRIPTS & ORDERS & PLEADINGS
MONTHYEARML20206U0471999-04-20020 April 1999 Council Order 731 Recommending Governors Approval of Amend of Site Certification Agreement for Satsop Power Plant Site ML20206U0291999-04-15015 April 1999 Council Order 731 Recommending Governors Approval of Amend of Site Certification Agreement for Satsop Power Plant Site ML20202C7941999-01-22022 January 1999 Order Revoking Const Permit CPPR-154.Orders That Subj Const Permit Terminated,For Listed Reasons.Order Effective Upon Date of Issuance ML20129D3991996-10-16016 October 1996 Memorandum & Order (Withdrawal of Application).* Grants Applicant Motion for Withdrawal of OL Application & Terminates Proceeding.W/Certificate of Svc.Served on 961016 ML20116N5501996-08-16016 August 1996 Motion for Withdrawal of Application.* Requests Issuance of Order Authorizing Withdrawal of OL Application at Issue & Terminating Proceeding.W/Certificate of Svc & Notice of Appearance ML20154D2801988-05-16016 May 1988 Order Extending Const Completion Date from 850101 to 990701, Per Util 841102 & 860310 Requests ML20133F6311985-10-0909 October 1985 Notice of Withdrawal of Appearance in Proceeding.Certificate of Svc Encl ML20090J7761984-05-0707 May 1984 Motion to Be Admitted as Interested State,Per Section 2.715(c) of NRC Rules of Practice ML20087P8581984-04-0404 April 1984 Response to 840320 Appeal Taken by Applicant from ASLB 840302 Order Granting Intervention on Remand from Aslab. Coalition Provided Info Detailed Enough to Determine Smith Educ & Experience Sufficient.Certificate of Svc Encl ML20087P8721984-04-0404 April 1984 Response Opposing Applicant 840320 Motion for Reconsideration of Memorandum & Order Granting Petitioner Intervenor Status.Certificate of Svc Encl ML20087H7761984-03-20020 March 1984 Notice of Appeal of ASLB 840302 Memorandum & Order Admitting Coalition for Safe Power as Intervenor.Certificate of Svc Encl ML20087H7791984-03-20020 March 1984 Brief in Support of Notice of Appeal of ASLB 830302 Memorandum & Order.Aslb Abused Discretion by Reinstating Order Granting Petitioner Intervenor Status.Aslb 830302 Memorandum & Order Should Be Vacated.W/Certificate of Svc ML20087H8021984-03-20020 March 1984 Motion for Reconsideration of Memorandum & Order Granting Petitioner Intervenor Status &/Or for Referral or Certification of Question of Whether Limitation Should Be Placed on Petitioner Participation.W/Certificate of Svc ML20086L2681984-02-0606 February 1984 Response Opposing Intervenor 840110 Suppl to Petition for Leave to Intervene.Petitioner Failed to Establish Solid Basis.Certificate of Svc Encl ML20083J1311984-01-10010 January 1984 Suppl to Petition of Coalition for Safe Power for Leave to Intervene & Request for Hearing,Per ASLB 831206 Order.Certificate of Svc Encl ML20082M7741983-12-0202 December 1983 Amend to Svc List,Adding N Bell.Certificate of Svc Encl ML20081J8621983-10-27027 October 1983 Answer to Applicant Appeal of ASLB 830421 & 0927 Orders Granting Request for Hearing & Petition for Leave to Intervene.Petitioner Failure to Intervene in Allotted Time Was Mere Oversight.Aslab Should Affirm ASLB Orders ML20078H2501983-10-12012 October 1983 Notice of Appeal of ASLB 830421 & 0927 Memoranda & Orders Admitting Coalition for Safe Power as Intervenor.Order of 830421 Should Be reversed,830927 Order Vacated & Proceeding Dismissed.Certificate of Svc Encl ML20078H1831983-10-12012 October 1983 Brief Supporting Util 830915 Notice of Appeal from ASLB 830421 & 0927 Memoranda & Orders Admitting Coalition for Safe Power as Party.Aslb Abused Discretion by Granting Untimely Petition.Certificate of Svc Encl ML20083D1731983-10-0404 October 1983 Draft Executive Board Resolution 142 Re Implementation of Extended Const Delay.Managing Director Directed to Resolve Dispute Re Disapprovals of Proposed Annual & Const Budget ML20076K3731983-07-0606 July 1983 Response Opposing Coalition for Safe Power Suppl to Petition to Intervene & Request for Hearing.Contentions Fail to Specify Bases.Certain Contentions Impermissibly Vague. Certificate of Svc Encl ML20024B6921983-07-0606 July 1983 Response Opposing Coalition for Safe Power Contentions in Supplemental Petition to Intervene.Intervenor Status Should Be Denied.Certificate of Svc Encl ML20079R2251983-06-15015 June 1983 Suppl to 830218 Petition to Intervene,Consisting of Proposed Contentions.Certificate of Svc Encl ML20073S2101983-05-0505 May 1983 Joint Util,Nrc & Coalition for Safe Power Recommended Schedule for Submission of Proposed Contentions & Subsequent Responsive Filings & for Time & Place for Holding Prehearing Conference.Certificate of Svc Encl ML20079P7231983-05-0505 May 1983 Submits Schedule for Submission of Proposed Contentions by Petitioner & Subsequent Responsive Filings of Other Parties & Time & Place for Holding Special Prehearing Conference. Montesano,Wa Recommended.Certificate of Svc Encl ML20071D5331983-03-0909 March 1983 Notice of Appearance in Proceeding.Certificate of Svc Encl ML20071D5771983-03-0909 March 1983 Answer Opposing Coalition for Safe Power 830222 Request for Hearing & Petition to Intervene Re OL Application.Clear Legal Interest Not Established.Good Cause Not Shown for Late Intervention.Certificate of Svc Encl ML20072B6381983-02-18018 February 1983 Petition of Coalition for Safe Power for Leave to Intervene & Request for Hearing Re OL Application.Certificate of Svc Encl ML20054M7711982-07-0909 July 1982 Order Extending Time Until 820729 for Commission to Decide Whether to Review NRR Director Denial of N Bell,On Behalf of Coalition for Safe Power,10CFR2.206 Petitions ML20054H8821982-06-16016 June 1982 Director'S Decision DD-82-6 Denying N Bell Petitions on Behalf of Coalition for Safe Power to Revoke CP on Basis of Matl False Statements in Application for Extension of CP ML20040C9041981-11-0606 November 1981 Order Approving 810406 Agreement Entitled Clarification of Wallace/Superior Policy Re Employee Reporting of Quality Violations. Agreement Encl ML20098D0881980-04-25025 April 1980 MOU Between WPPSS & Doe,Acting by & Through BPA Re Roles & Responsibilities Under Project Agreements Concerning Const & Operation of Net Billed Projects ML20062A5441978-10-0202 October 1978 Request by Citizens for a Safe Environ of 780817 Re ALAB-501 Dismissed for Want of Jurisdiction ML20098C7661977-07-13013 July 1977 Affidavit of Jd Perko Re Corrections to Financial Qualifications Testimony ML20098C6911976-05-14014 May 1976 Affidavit of DW Connor Re Need for Proposed Units.Based on West Group Forecast Projection of Energy Loads & Capacities, Probable Need for Units 3 & 5 Greater than Yr Ago 1999-04-20
[Table view] Category:ORDERS
MONTHYEARML20202C7941999-01-22022 January 1999 Order Revoking Const Permit CPPR-154.Orders That Subj Const Permit Terminated,For Listed Reasons.Order Effective Upon Date of Issuance ML20129D3991996-10-16016 October 1996 Memorandum & Order (Withdrawal of Application).* Grants Applicant Motion for Withdrawal of OL Application & Terminates Proceeding.W/Certificate of Svc.Served on 961016 ML20154D2801988-05-16016 May 1988 Order Extending Const Completion Date from 850101 to 990701, Per Util 841102 & 860310 Requests ML20054M7711982-07-0909 July 1982 Order Extending Time Until 820729 for Commission to Decide Whether to Review NRR Director Denial of N Bell,On Behalf of Coalition for Safe Power,10CFR2.206 Petitions ML20040C9041981-11-0606 November 1981 Order Approving 810406 Agreement Entitled Clarification of Wallace/Superior Policy Re Employee Reporting of Quality Violations. Agreement Encl ML20062A5441978-10-0202 October 1978 Request by Citizens for a Safe Environ of 780817 Re ALAB-501 Dismissed for Want of Jurisdiction 1999-01-22
[Table view] |
Text
'
4
, 7590-01 1
WASHINGTON PUBLIC POWER SUPPLY SYSTEM PACIFIC POWER AND LIGHT COMPANY PORTLAND GENERAL ELECTRIC COMPANY l l
PUGET SOUND POWER AND LIGHT COMPANY J THE WASHINGTON WATER POWER COMPANY ;
WASHINGTON PUBLIC POWER SUPPLY SYSTEM NUCLEAR PROJECT NO. 3 DOCKET NO. 50-508 ORDER EXTENDING CONSTRUCTION COMPLETION DATE Washington Public Power Supply System is the current holder of j Constrstion Permit No. CPPR-154,* issued by the Nuclear Regulatory Commission on April 11, 1978, for construction of WPPSS Nuclear Project No. 3 (WNP-3).
The facility is presently under construction at the applicant's site in south-eastern Grays Harbor County, Washington, On November 2, 1984, the Washington Public Power Supply System (WPPSS or the applicant) filed a request for an extension of the completion date. On March 10, 1986, the applicant requested a revision to the date requested in the
! earlier submittal. The extension has been requested because construction has !
1
., been delayed by the following events:
- 1. The temporary lack of demand for the energy to be produced by WNP-3;
- 2. The temporary inability to firance the continued construction from l
Benneville Power Administration (BPA) revenues; j 1
- 3. Recomendations of the BPA to WPPSS that the construction restart be i 1 delayed until 1994 due to the latest regional planning; l
- 4. The c.110wance of a 54-month construction period to complete WNP-3 and a margin of uncertainties such as those associated with regional l I
0 hbh D A
I
l 7590-01 1
i l load growth or time to startup the project to full construction l
l making a revised construction completion date of July 1, 1999. l Although the applicant has not submitted a specific requert to have WNP-3 be made a deferred plant pursuant to the Comission's Policy Statenent on Deferred Plants, 52 FR 38077, October 14, 1987, it has provided all the l
information necessary to allow the staff to conclude that WNP-3 is a deferred plant. Accordingly, the NRC staff has determined that WNP-3 is a deferred plant as defined by the Comission in the policy and that it is, therefore, subject to any applicable provisi,ons of the policy set forth there.
Good cause has been shown for the delays; the causes were beyond the control of the applicant; and the requested extension is for a reasonable period, the bases for which are set forth in the staff's evaluation of the reauest for extension.
Pursuant to 10 CFR 51.32, the Comission has determined that extending the r,onstruction completion date will have no significant impact on the environnent (53 FR 16799 dated May 11, 1988).
The NRC staff safety evaluation of the request for extension of the construction permit is available for public inspection at the Comission's ;
1 Public Document Room, 1717 H Street, N.W. Washington, D.C. 20555 and at the Local Public Document Roon at W. H. Memoris Library, 125 Main Street, South, Montesano, Washington 28523.
l l
l
d ' .
7590-01
' ~
I IT IS HEREBY ORDERED THAT the, latest completion date for Construction Permit No. CPPR-154 is extended from January 1, 1985 to July 1, 1999.
FOR THE NUCLEAR REGULATORY COMMISSION l 1
\
k , l9$
Denn s M. Crutchf e , DigEctor '
Division of Reactor Projdts - !!!,
IV, Y and Special Projects Date of Issuance: thy 16, 1988 4
I 1
i i
f i
l 1
i d
a
v 7
7590-01 tlASHINGTON PUBLIC POWER SUPPLY SYSTEM PACIFIC POWER AND LIGHT COMPANY PORTLAND GENERAL ELECTRIC COMPANY <
PUGET SOUND POWER AND LIGHT COMPANY THE WASHINGTON WATER POWER COMPANY WASHINGTON PUBLIC POWER SUPPLY SYSTEM NUCLEAR PROJECT NO. 3 DOCKET NO. 50-508 ORDER EXTENDING CONSTRUCTION COMPLETION DATE Washington Public Power Supply System is the current holder of Construction Permit No. CPPR-154,. issued by the Nuclear Regulatory Commission on April 11, 1978, for construction of WPPSS Nuclear Project No. 3 (WNP-3).
The facility is presently under construction at the applicant's site in south- :
- eastern Grays Harbor County, Washington, On November 2, 1984, the Washington Public Power Supply System (WPPSS or the applicant) filed a request for an extension of the coupletion date. On l March 10, 1986, the applicant requested a revision to the date requested in the i earlier submittal. The extension has been requested because construction has been delayed by the fo11 ewing events
- 1. The temporary lack of demand for the energy to be produced by WNP-3;
- 2. The temperary inability to finance the continued construction fron
- Bonneville Power Administration (BPA) revenues; 1 i j 3. Reconmendations of the BPA to WPPSS that the construction restart be i delayed until 1994 due to the latest regional planning; !
- 4. The allowance of a 54-month construction period to complete WNP-3 and a margin of uncertainties such as those associated with regional l
7590-01 2
load growth or time to startup the project to full construction making r revised construction completion date of July 1, 1999.
Although the applicant has not submitted a specific request to have WNP-3 be made a deferred plant pursuant to the Comission's Policy Statement on Deferred Plants, 52 FR 38077, October 14, 1987, it has provided all the information necessary to allow the staff to conclude that WNP-3 is a deferred plant. Accordingly, the NRC staff has determised that WNP-3 is a deferred plant as defined by the Comission in the policy and that it is, therefore. l subject to any applicable provisions of the policy set forth thert. !
Good cause has been shown for the delays; the causes were beyond the control of the applicant; and the requested extension is for a reasonable period, the bases for which are set forth in tne staff's evaluation of the !
request for extension.
1 Pursuant to 10 CFR 51.32, the Comission has determined that extending I l
the construction completion date will have no significant impact on the l environment (53 FR 16799 dated May 11, 1988).
The NRC staff safety evaluation of the request for extension of the construction permit is available for public inspection at the Comission's Public Docunent Room, 1717 H Street, N.W. Washington, D.C. 20555 and at the Local Public Document Room at W. H. Memorial Library, 125 Main Street, South, Montesano, Washington 28523. ,
I l
I l
j
J t
7590-01 1
i l
1 IT IS HEREBY ORDERED THAT the latest completion date for Construction !
Permit No. CPPR-154 is extended from January 1, 1985 to July 1, 1999.
FOR THE NUCLEAR REGULATORY COMMISSION i
rk Dennis M. Crutchfie d, Dir or Division of Reactor Projec s - III, .
IV, Y and Special Projects l i Date of Issuance: May 16, 1988 l j
4 i
j i l l
I l'
I
- _ _ - , _ _ .