ML20133E527
| ML20133E527 | |
| Person / Time | |
|---|---|
| Issue date: | 09/19/1985 |
| From: | Odonnell W, Smith P NRC OFFICE OF ADMINISTRATION (ADM), O'DONNELL CONSULTING ENGINEERS, INC. |
| To: | |
| Shared Package | |
| ML20133E520 | List: |
| References | |
| CON-FIN-D-1642, CON-NRC-04-85-123, CON-NRC-4-85-123 NUDOCS 8510090423 | |
| Download: ML20133E527 (14) | |
Text
.
o AWARD / CONTRACT M'&C,0M" ^C,','c,^,"y,8 S 0 0"D'"
) 1g
- 5. CONT 81 ACT S r.r. mese Asees JNO. 4. EFFECT eve DATE .. mEGulleT eO*e/pumCMA5E REQUE51/PmOJEC T NO NRC-04-85-123 SEP 301985 5 eS&wED ev l 4. AOM eN.E M0 e V IF,.84a* Ilh.= Imas, di l
U.S. Nuclear Regulatory Commission Division of Contracts Washington, DC 20555
- 7. h Atst AmeO ?S""ESS O' Cont m ACTOm (N. , sesses, eery e..ary. Sener .=d IIP C.de s 4. OE Le vE m V 0'Donnell Consulting Engineers, Inc. O Foa oa'c'~ <a<= .
3611 Maplevue Drive e.DisCOve.Tromno YPAv.E~T.B OT Bethel Park, PA 15102 .
~
10 $UsusTINvOICE5 l 'T = "
- 4 e. pee .aer.e .#aee- 8 CODE or speeen.ds TO THE F AC.Lity CODE s a. s .. TOtwa.h rom ADOmESS $ Nome IN 12 an. PavuENT u= ELL eE asADE ev See Section F.2 See Section G
- 15.
AUT*~OmtTV FOm UlthG OTHE A TMAN FULL AND O*EN COweET4 l.. ACCOUNTafeG AND AppmOpme AT EON DAT A B&R fio. 601910 iousC noeun i O4iusC mNu i Fill D1642 M9,900 15A ITEW NO 158 $UPPLtES/5EnvlCES 15C. OUANTaTV 150.uNrT ISE UNIT PRICE ISF. AMOUNT The Contractor shall perform rese<irch entitled, " Extended Fatigue Life : valuation '
Methods for Aged LWR Components" in accordance with the schedule and the contrac ;or's proposal dated i April 21,1985, which is incorporated herein and made a part hereof.
StG. TOTAL AmeOueff OP CONTRACT > $4Q,qnq
- 16. TABLE O' CONTENTS Vil1EC l OE SCmiPTION lPAGE tsi VI l$EC l OE SCmiPTION 9Amt e = TME SCHE DULE lPAGE t$1 A PART 14 - CONTm ACT CLAUSES SOteCITATIONICONTRACT FOmW I 5 l t l CONTR ACT CLAUSES l 13
$UPPLIES Om $E RvlCES ANO PasCES/ COSTS 2 C pant ses - List Os DOCuwEsets. Euwesets A=O OTe.Em ATT ACm OEScalPTsON/SPE CS /WomK STATE ME NT 7 O lJ l LtST OF ATT ACHME NTS l ]4 PACK AGING ANO MAmalNG 9 E pant ev - mEPREstesTAveOns AseO smstavCTeows INSPECTION AND ACCEPTANCE o F et OE Live ntES Om PE mFOmMANCE mEPRESENTATIONS.CE RTIFICATION5 AND 3 OTHEm STATEMENTS OF OFFEmORS G CONTRACT AOuiNisTRATlON DATA 3 ".
lH SPEceAL CONTRACT mEOutatuf wTS n M INsTms . CONOS . ANO NOTICES TO OF FE moms EVALUATION F ACTORS FOm AwARO CONTMACTING OFFICER WilI C06998 ETE ITEet li on IS AS AWLICASL E a 7. O CO TmAC7On .ef aOT ATEO Aant NT C A -. i..
O A-Amo.c ' -d .m tui'.#.,'*.".#.de::::'.."'
. ".%". 'fa'.': tfr.f,7.T" ( Or *",,'f0".*.'.";" "r?*.* . p .
M AT:";.'r '?O.'"T "," T.f.; r.ry=7.'r~" T.'.i.W.'t: :::
. .e. . . ;
7.'1".'.".'" ::1',";."';;1'?.'# :::'t.'!
= .".'.g ge g ,,,g;, g,,.'.n - - - r..i.,llll""l1.*"".'l:'"a.'.'.LO g;,".;,,g.O.'.?'.Ji.t:f'.AO,e.g,0J"llf,
. .- :.:.:M
. % *" 'i:."?a.O."T'.!' '7.n';t.T":.t.7,0 *llL T A 8Tu"l""uiMOtTLJE .
O " tw F s'"Dou(Type p.enohkrifaW m n'c. w 30A.NAestOFCONT)RA T e*es OF F.C E m s , .w; 0%wu see.N ==
Cwwan ConTmAcTOm Fw, anW tw. " = u D. Th m son j noC. SATE sanwEn see. vMeTEO sT ATEs OF As.E meC A
&Y en DAf t 6.cwEn av c==
la u n w $s (g h-l2lg5 av h &..,~ L $ r $ , N e ., C.de m O m ., al/y 4/r NSpe 76.e43.s$3 PmEveOUS EOtTION4e49.e U #SAeLE 76-les STANOA.RD., C 6 APOAM as smE v. ..eis 8510090423 850919 e tr.8. Sevt.aguN.f P.sarte.6 offtCE ! 8909 e.-306J004915 P..esee.4 FAm4 CMI 93 H.(al PDR CONTR NRC-04 123 PDR '
NRC-04-85-123 Page 2 Section B - Supplies or Services and Prices / Costs B.1 Brief Description of Work The contractor shall conduct research entitled " Extended Fatigue Life Evaluation Methods for Aged LWR Components"
- 8.2 Total Price. . . . . . . . . . . . . . . . . . $49,900 Section C - Description / Specifications / Work Statement C.1 Statement of Work The work to be performed and the objectives to be met in this contract shall bethe to in accordance FY 1985 Small with the contractor's technical and cost proposal in response Business Innovation Research Program (SBIR) which is incorporated as attached (Attachment 5).
Section D - Packaging and Marking D.1 The contractor shall use standard commercial packaging for all items to be delivered. On the front of the package, the contractor shall clearly identify the contract number under which the product is being provided.
Section E - Inspection and Acceptance E.1 FAR Citations l
The contractor shall refer to Section I, Clause No. 52.252-2 for citations incorporated by reference.
4 Section F - Deliveries and Performance F.1 Reports, Documentation and Other Deliverable End Items
- a. Letter progress reports in three copies to the Project Officer and one copy to the Contracting Officer shall be due by November 30, 1985 and January 30, 1986 l
- b. A final report to include the results of the work performed under this contract shall be submitted to the project officer in one camera ready copy and three copies at the conclusion of this effort. In addition, one copy of the final report shall be submitted to the Contracting Officer on the completion date of the contract. 3 4
F.2 Place of Delivery The items to be furnished hereunder shall be delivered, with all transportation charges paid by the Contractor, to:
- 1. Copies to Project Officer:
NRC-04-85-123 Page 3 U.S.. Nuclear Regulatory Comission ATTN: G. H. Weidenhamer Office of Nuclear Regulatory Research Division of Engineering Technology Mail Stop: NL 5650 Washington, DC 20555
- 2. Copies to Contracting Officer:
U.S. Nuclear Regulatory Comission ATTN: Contracting Officer Division of Contracts Mail Stop: AR 2223 Washington, DC 20555 F.3 Duration of Contract Period This contract shall become effective on the effective date as specified in Block 3 of the SF26, and shall continue to completion thereof, which is six months after said contract is effective.
F.4 FAR Citations The contractor shall refer to Section I, Clause No. 52.252-2 for citations incorporated by reference.
Section G - Contract Administration Data G.1 Technical Direction A.
Performance of the work under this contract shall be subject to the technical direction of the NRC Project Officer named in Section G.2 of this contract. The tem " Technical Direction" is defined to include the following:
1.
Technical direction to the Contractor which shifts work emphasis between areas of work or tasks, requires pursuit of certain lines of inquiry, fills in details. or otherwise serves to accomplish the contractual scope of work.
- 2. Providing assistance to the Contractor in the preparation of drawings, specifications or technical portions of the work description.
- 3. Review and where required by the contract, approval of technical reports, drawings, specifications and technical information to be delivered by the Contractor to the Government under the contract.
B.
Technical direction must be within the general scope of work stated in the contract. The Project Officer does not have the authority to and may r.ot issue any technical direction which:
NRC-04-85-123 Page 4
- 1. Constitutes an assignment of additional work outside the general scope of the contract.
- 2. Constitutes a change as defined in the clause of the General Provisions, entitled " Changes."
- 3. In any way causes an increase or decrease in the total estimated contract cost, the fixed fee, if any, or the time required for contract perfonnance.
- 4. Changes any of the expressed terms, conditions or specifications of the contract.
C.
ALL TECHNICAL DIRECTIONS SHALL BE ISSUED IN WRITING BY THE PROJECT OFFICER OR SHALL BE CONFIRMED BY SUCH PERSON IN WRITING WITHIN TEN (10) WORKING DAYS AFTER VERBAL ISSUANCE.A copy of said written direction shall be submitted to the Contracting Officer.
The Contractor shall proceed promptly with the perfonnance of technical directions duly issued by the Project Officer in the manner prescribed by this article and within such person's
- authority under the provisions of this article.
If, in the opinion of the Contractor, any instruction or direction issued by the Project Officer is within one of the categories as defined in B(1) through (4) above, the Contractor shall not proceed but shall notify the Contracting Officer in writing within five (5) working days after the receipt of any such instruction or direction and shall request the Contracting Officer to modify the contract accordingly. Upon receiving such notification from the Contractor, the Cortrecting Officer shall issue an appropriate contract modification or advise the Contractor in writing that, in the Contracting Officer's opinion, the technical direction is within the scope of this article and does not constitute a change under the Changes Clause.
D.
Any unauthorized comitment or direction issued by the Project Officer may result in an unnecessary delay in the Contractor's perfortnance, and may even result in the Contractor expending funds for unallowable costs under the contract.
E. A failure of the parties to agree upon the nature of the instruction or direction or upon the contract action to be taken with respect thereto shall be subject to the provisions of the contract clause entitled " Disputes."
G.2 Project Officer A. The individual (s) listed in "B" below is (are) hereby designated as the Contracting Officer's authorized representative (hereinafter called Project Officer) for
NRC-04-85-123 Page 5 technical. aspects of this contract. The Project Officer is not authorized to approve or request any action which results in or could result in an increase in contract cost; or terminate, settle any claim or dispute arising under the contract, or issue any unilateral directive whatever.
The Project Officer is responsible for: (1) monitoring the Contractor's technical progress, including surveillance and assessment of performance, and recommending to the Contracting Officer changes in requirements; (2) interpreting the scope of 1
wcrk; (3) performing technical evaluation as required; (4) performing technical inspections and acceptances required by this contract; and (5) assisting the Contractor in the resolution of technical problems encountered during performance. Within the purview of this authority, the Project Officer is authorized to review all costs requested for reimbursement by Contractors and submit recomendations for approval, disapproval, or suspension for supplies / services required under the contract. The Contracting Officer is responsible for directing or negotiating any changes in terms, conditions, or amounts cited in the contract.
For guidance from the Project Officer to the Contractor to be valid, it must: (1) be consistent with the description of work set forth in the contract; (2) not constitute new assignment of work or change to the expressed terms , conditions or specifications incorporated into this contract; (3) not constitute a basis for an extension to the period of performance or contract delivery schedule; and, as stated above, (4) not constitute a basis for any increase in the contract cost.
B. Name and Mail Code: G. H. Weidenhamer Office Address: U.S. Nuclear Regulatory Commission Office of Nuclear Regulatory Research Mail Stop 1130 SS Washington, DC 20555-G.3 Invoice Requirements Invoices shall be submitted in an original and 4 copies to:
U.S. Nuclear Regulatory Commission Division of Accounting and Finance Office of Resource Management ATTN: GOV /COM Accounts Section Washington, D.C. 20555. l To constitute a proper invoice, the invoice must include the '
following infornetion and/or attached documentation:
(1) Name of the business concern and invoice date.
i i
{
(
NRC-04-85-123 Page 6 (2) Contract number or other authorization for delivery of property or services.
(3) Description price and quantity of property and services actually delivered or rendered.
(4) Shipping and payment terms.
(5) Name (where practicable), title, phone numb.er, and complete mailing address of responsible official to whom payment is to be sent.
(6) Other substantiating documentation or infonnation as required by the contract.
G.4 Payment (a) Payment shall be made in the amount of $16,600 to the contractor within 30 days after receipt of each of the two letter progress reports as required in Section F.1.a. Payment shall not be made prior to receipt of said progress reports.
i (b) Final payment shall be made in the amount of $16,700 to the {
contractor within 30 days after receipt of the final report as )
required in Section F.1.b.
(c) All contractor invoices shall identify the contract number and the monthly letter progress report for which payment is claimed.
1 (d) If this contract provides for a discount, the contract shall indicate the contract's discount terms (Block 9 of Standard Form 26) on the face page of the invoice.
G.5 Interest on Overdue Payments (a) The Prompt Payment Act, Public Law 97-177 (96 STAT. 85, 31 USC 1801) is applicable to payments under this contract and requires the payment of interest to _ contractors on overdue payments and improperly taken discounts.
(b) Determinations of interest due will be made in accordance with the provisions of the Prompt Payment Act and Office of Management and Budget Circular A-125, Vol. 47 Federal Register 37321 August 25, 1982. Among other considerations, OMB Circular A-125 provides that:
(1) Interest penalties a re not required when payment is delayed because of a disagreement over the amount of payment or other issues concerning compliance with the terms of the contract.
NRC-04-85-123 Page 7 (2) Whenever a proper invoice is paid after the due date plus 15 days, interest will be included with the payment at the interest rate applicable on the payment date. Interest will be computed from the day after the due date through the payment date.
G.6 Method of Payment (a) Payment under this contract will be made by wire transfer through the Treasury Financial Communications System for each individual payment in excess of $25,000 and by Treasury check for each individual payment of $25,000 or less.
(b) Within seven days after the effective date of the contract, the Contractor shall forward the following infonnation in writing to the Contracting Officer to facilitate wire transfer of contract payments. In the event that the Contractor's financial institution has access to the Federal Reserve Communications System, Contractor shall complete all items except items 7 - 9. In the event the Contractor's financial institution does not have access to the Federal Reserve Comunications System, Contractor shall complete all items except item 4.
- 1. Name and address of organization
- 2. Contact person and telephone number
- 3. Name and address of financial institution
- 4. Financial institutions's 9-digit ABA identifying number for routing transfer of funds
- 5. Telegraphic abbreviation of financial institution
- 6. Account number at your financial institution your financial institution receives electronic funds transfer messages through, if it does not have access to the Federal Reserve Comunications System
- 7. Name and address of the correspondent financial institution your financial institution receives electronic funds transfer messages through, if it does not have access to the Federal Reserve Comunications System
- 8. Correspondent financial institution 9-digit ABA identifying number for routing transfer of funds
- 9. Telegraphic abbreviation of correspondent financial institution i
- 10. Signature and title of person supplying this infonnation
NRC-04-85-123 Page 8 (c) Any changes to the infonnation furnished under paragraph (b) of this clause shall be furnished to the Contracting Officer in 1
writing. It is the Contractor's responsibility to furnish these changes promptly to avoid payments to erroneous bank accounts.
Section H - Special Contract Requirements H.1 Key Personnel (a) The following individuals are considered to be essential to the successful performance of the work hereunder.
William J. O'Donnell The Contractor agrees that such personnel shall not be removed from the contract work or replaced without compliance with paragraphs (b) and (c) hereof.
(b) If one or more of the key personnel for whatever reason becomes, or is expected to become, unavailable for work under this contract for a continuous period exceeding 30 work days, or is expected to devote substantially less effort to the work than indicated in the proposal or initially anticipated, the Contractor
' shall inmediately notify the Contracting Officer and shall, subject to the concurrence of the Contracting Officer or his authorized representative, promptly replace such personnel with personnel of at least substantially equal ability and qualifications.
(c) All requests for approval of substitutions hereunder must be in writing and provide a detailed explanation of the circumstances necessitating the proposed substitutions. They must contain a complete resume for the proposed substitute, and other infonnation requested by the Contracting Officer or needed by him to approve or disapprove the proposed substitution. The Contracting Officer or his authorized representative will evaluate such requests and promptly notify the Contractor of his approval or disapproval thereof in writing.
(d) If the Contracting Officer detennines that suitable and timely replacement of key personnel who have been reassigned, terminated or have otherwise become unavailable for the contract work is not reasonably forthcoming or that the resultant reduction of productive effort would be so substantial as to impair the successful completion of the contract or the service order, the contract may be tenninated by the Contracting Officer for default or for the convenience of the Government, as appropriate, or, at the discretion 1
of the Contracting Officer if he finds the Contractor at fault for the condition, the contract price or fixed fee may be equitably adjusted downward to compensate the Government for any resultant delay, loss or damage.
NRC-04-85-123 Page 9 H.2 Consultant or Other Comparable Employment Services of Contractor Employees (0MB Clearance Number 3150-0112)
The Contractor shall require all employees who are employed full-time (an individual who performs work under the cost-type contract on a full-time annual basis) or part-time (50 percent or more of regular annual compensation received under terms of a contract the with theall Contractor Comission) on the contract work to disclose to consultant or other comparable employment services which the employees proposed to undertake for others. The Contractor shall transmit to the Contracting Officer all infomation obtained from such disclosures. The Contractor will require any employee who will be employed full-time on the contract to agree, as a condition of his participation in such work, that he will not perform consultant or other comparable employment services for another Commission cost-type Contractor under its contract with the Comission except with the prior approval of the Contractor.
H.3 Safety, Health, and Fire Protection The Contractor shall take all reasonable precautions in the performance of the work under this contract to protect the health and safety of employees and of members of the public and to minimize danger from all hazards to life and property and shall comply with all health, safety, and fire protection regulations and requirements (including reporting requirements) of the Comission and the
> Department of Labor.
In the event that the Contractor fails to comply with said regulations or requirements, the Contracting Officer may, without prejudice to any other legal or contractual rights of the Comission, issue an order stopping all or any part of the work; thereafter, a start order for resumption of work may be issued at the discretion of the Contracting Officer. The Contractor shall make no claim for an extension of time or for compensation or damages by reason of or in connection with such work stoppage.
H.4 Dissemination of Contract Information (0M8 Clearance Number 3150-0112) 1 The Contractor shall not publish, permit to be published, or disseminate to the public any infomation, oral or written, concerning the work performed under this contract without the prior written consent of the Contracting Officer. Two copies of any infomation proposed to be published or disseminated shall be submitted to the Contracting Officer. Failure to comply with this clause shall be grounds for temination of this contract.
H.S Private use of Contract Infonnation and Data Except as otherwise specifically authorized by Section H.,
publication of contract work of this contract, or as othemise approved by the Contracting Officer, information and other data developed or acquired by or furnished the Contractor in the
NRC-04-85-123
_ Page 10 perfomance of this contract, shall be used only in connection with the work under this contract.
H6 Drawings, Designs, and Specifications All drawings , sketches, designs, design data, specifications, notebooks, tech 91 cal and scientific da ta , and all photographs, negatives, reports, findings, recomendations, data and memoranda of every description relating thereto, as well as all copies of the foregoing relating tc the work or any part thereto', shall be subject to inspection by the Comission at all reasonable times (for which inspection the proper facilities shall be afforded the Comission by the Contractor and its subcontractors), shall be the property of the Government and may be used by the Government for any purpose whatsoever without any claim on the part of the Contractor and its subcontractors and vendors for additional compensation and shall, subject to the right of the Contractor to retain a copy of said material for its own use, be delivered to the Government, or otherwise disposed of by the Contractor either as the Contracting Officer may from time to time direct during the progress of the work or in any event as the Contracting Officer shall direct upon completion or termination of this contract. The Contractor's right of retention and use shall be subject to the security, patent, and use of infomation provisions, if any, of this contract.
H.7 Proprietary Data and Confidential Information In connection with the performance of the work under this contract, the Contractor may be furnished, or may develop or acquire, proprietary data (trade secrets) or confidential or privileged tet.hnical, business, or financial information, including Commission plans, policies, reports, financial plans, internal data protected by the Privacy Act of 1974 (P.L.93-579), or other infonnation which has not been released to the public or has been determined by the Comission to be otherwise exempt from disclosure to the public.
Contractor agrees to hold such information in confidence and not to directly or indirectly duplicate, disseminate, or disclose such -
infomation in whole or in part to any other person or organization except as may be necessary to perform the work under this contract.
Contractor agrees to return such information to the Comission or otherwise dispose of it either as the Contracting Officer may from time to time direct during the progress of the work or in any event as the Contracting Officer shall direct upon completion or tennination of this contract. Failure to comply with this clause shall be grounds for termination of this contract.
H.8 Contractor Organizational Conflicts of Interest (OMB Clearance Number 3150-0112)
(a) Purpose. The primary purpose of this clause is to aid in ensuring that the Contractor: (1) Is not placed on a conflicting role because of current or planned interest (financial, contractual, organizational, or otherwise) which relate to the work under this
NRC-04-85-123
_ Page 11 contract, and (2) does not obtain an unfair competitive advantage over other parties by virtue of its perfomance of this contract.
(b) Scope. The restrictions described herein shall apply to performance or participation by the Contractor as defined in 41 CFR 920-1.5402(f) in the activities covered by this clause.
(c) Work for Others. Notwithstanding any other provision of this contract, during the term of this contract, the Contractor agrees to forgo entering into consulting or other contractual arrangements with any firm or organization, the result of which may give rise to a conflict of interest with respect to the work being performed under this contract. The Contractor shall ensure that all employees who are employed full time under this contract and employees designated as key personnel, if any, under this contract abide by the provision of this clause. If the Contractor believes with respect to itself or any such employee that any proposed consultant or other contractual arrangement with any fim or organization may involve a potential conflict of interest, the Centractor shall obtain the written approval of the Contracting Officer prior to execution of such contractual arrangement.
(d) Disclosure af ter award.
(1) The Contractor warrants that to the best of its knowledge and belief and except as otherwise set forth in this contract, it does not have any organizational conflicts of interest, as defined in 41 CFR 20-1.5402(a).
(2) The Contractor agrees that if after award it discovers organizational conflicts of interest with respect to this contract, it shall make an immediate and full disclosure in writing to the Contracting Officer. This statement shall include a description of the action which the Contractor has taken or proposes to take to avoid or mitigate such conflicts.
The NRC may, however, terminate the contract for convenience if it deems such termination to be in the best interests of the Government.
(e) Access to and use of infortnation.
(1) If the Contractor in the perfomance of this contract obtains access to infomation, such as NRC plans, policies, reports, studies, financial plans, internal data protected by the Privacy Act of 1974 (Pub. L.93-579), or data which has not been released to the public, the Contractor agrees not to:
(1) Use such information for any private purpose until the infomation has been released to the public; (ii) compete for work for the Commission based on such information for a period of six (6) months after either the completion of this contract or the release
~
v I
NRC-04-85-123
_ Page 12 of such infomation to the public, whichever is first; (iii) submit an unsolicited proposal to the Government based on such information until one year after the release of such information to the public, or i
(iv) release the information without prior written approval by the Contracting Officer unless such information has previously been released to the public by the NRC.
' (2) In addition, the Contractor agrees that to the extent it receives or is given access to proprietary data, data protected by the Privacy Act of 1974 (Pub. L.93-579), or other confidential or privileged technical, business, or financial information under this contract, the Contractor shall treat such infomation in accordance with restrictions placed on use of the infomation.
(3) The Contractor shall have, subject to patent and security provisions of this contract, the right to use technical data it produces under this contract for private purposes provided that all requirements of this contract have been met.
(f) Subcontracts. Except as provided in 41 CFR 20-1.5402(h), the Contractor shall include this clause, including this paragraph, in i
subcontracts of any tier. The terms " contract," " Contractor," and
" Contracting Officer." shall be appropriately modified to preserve the Government's rights.
(g) Remedies. For breach of any of the above prescriptions or for intentional nondisclosure or misrepresentation of any relevant interest required to be disclosed concerning this contract or for t
such erroneous representations as necessarily imply bad faith, the '
! Government may teminate the contract for default, disqualify the Contractor from subsequent contractual efforts, and pursue other remedies as may be permitted by law or this contract.
i (h) Waiver. A request for waiver under this clause shall be
' directed in writing through the Contracting Officer to the Executive Director for Operations (ED0) in accordance with the procedures outlined in 620-1.5411.
i
\
NRC-04-85-123
_ Page 13 PART II - CONTRACT CLAUSES Section I - Contract Clauses 52.246-4 INSPECTION OF SERVICES--FIXED-PRICE. (APR1984)
Section F 52.212-13 STOP-WORK ORDER. (APR 1984)
Section I 4
52.202-1 DFCINITIONS. (APR 1984) 52.203-1 0FFICIALS NOT TO BENEFIT. (APR1984, 52.203-3 GRATUITIES. (APR1984) 52.203-5 COVENANT AGAINST CONTINGENT FEES. (APR 1984)
~
52.215-1 EXAMINATION OF RECORDS BY COMPTROLLER GENERAL. (APR 1984) 52.215-31 WAIVER OF FACILITIES CAPITAL COST OF MONEY.(APR 1984) 52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS AND SMALL
' DISADVANTAGED BUSINESS CONCERNS. (APR1984) 52.219-13 UTILIZATION OF WOMEN-0WNED SMALL BUSINESSES. (APR 1984 52.220-3 UTILIZATION OF LABOR SURPLUS AREA CONCERNS.
51.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES.
(APR1984))
(APR 1984) 52.222-3 CONVICT LABOR. (APR 1984) 52.222-26 EQUAL OPPORTUNITY. (APR 1984) 52.222-35 AFFIRMATIVE ACTION FOR SPECIAL DISABLED AND VIETNAM ERA VETERANS (APR 1984) 52.222-36 AFFIRMATIVE ACTION FOR HANDICAPPED WORKERS (APR 1 52.227-1 AUTHORIZATION AND CONSENT. ( APR 1984)--Alternate I. (APR 1984) 52.227-2 NOTICE AND ASSISTANCE, REGARDING PATENT AND COPYRIGHT INFRINGEMENT. (APR 1984) 52.227-11 PATENT RIGHTS--RETENTION BY THE CONTRACTOR (SHORT (APR 1984) 52.229-3 FEDERAL, STATE, AND LOCAL TAXES (APR 1984) l 52.229-5 TAXES--CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO. (APR 1984) l 52.232-2 PAYMENTS UNDER FIXED-PRICE RESEARCH AND DEVELOPMENT CONTRACTS. (APR 1984) 52.232-8 DISCOUNTS FOR PROMPT PAYMENT. (APR1984) 52.232-17 INTEREST. (APR1984) 52.232-23 ASSIGNMENT OF CLAIMS. (APR 1984)--Alternate I. (APR 1984) 52.233-1 DISPUTES. (APR 1984) 52.243-1 CHANGES--FIXED-PRICE. (APR1984)--Alternate 5. (APR 1984) 52.246-25 LIMITATION OF LIABILIT)--SERVICES. (APR 1984) 52.247-63 PREFERENCE FOR U.S.-FLAG AIR CARRIERS. (APR1984) 52.249-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE)(SHORTFORM). (APR 1984) 52.249-8 DEFAULT (FIXED-PRICESUPPLYANDSERVICE).(APR1984) 1 - . _ . _ _
- = . _ _ - . . .
- (
NRC-04-85-123 Page 14 PART III - LIST OF DOCUMENTS, EXHIBITS, AND OTHER ATTACHMENTS Section J - List of Attachments Attachment Number Title 1 NRC Organization Chart 2 NRC Contractor Organizational Conflicts of Interest
, (41 CFR Part 20) 3 NRC Manual Chapter 3202 4 Billing Instructions 5 Contractor's technical and cost proposal in response to the FY 1985 Small Business Innovation Research Program (SBIR) entitled " Extended Fatigue Life 1
Evaluation Methods for Aged LWR Components" 1
9 n ------ .,_<,e r - - - - - , . , - , -v , - - - . - - - - - , - - , ,- - - , - - - - - - - , - - - - - , > - - - - - - - - -
- - , - - - , -